An Update on Prescription – The Most Important Issue

In Couvillion Group, LLC v. Plaquemine Parish Government, the Louisiana Court of Appeals for the Fourth Circuit addressed whether the general contractor could recover “pass-through claims” against the owner where those claims would be time-barred if brought directly by the subcontractors. “Pass-through claims” have been described as damage claims that subcontractors “pass through” to the contractor to prosecute an action against the project owner to recover those damages.

In Couvillion, the contractor sued the Parish for delay damages. The trial court awarded $2,782,724 in delay damages, $300,000 of which was for delays incurred by two of the subcontractors.

On appeal, the Parish argued that the contractor could not recover the pass-through claims because any claims for delay that the subcontractors had against the contractor were prescribed (time-barred). The subcontractors sent demand letters after substantial completion in 2013 but did not file suit against the contractor. Under Louisiana law, contract claims are subject to a 10-year prescriptive period. The Parish asserted that by the time trial occurred in 2024, the subcontractor claims had prescribed.

The Fourth Circuit recognized that subcontractors often pass their claims through the contractor to prosecute against the owner to recover those damages. The contractor included those claims in the lawsuit filed against the owner in 2015. When several parties share a cause of action, suit by one party interrupts prescription as to all parties. As such, the court held that prescription was interrupted, and the contractor could recover the pass-through claims against the owner.

This case highlights the importance of identifying and properly preserving pass-through claims early in litigation.

References:

Couvillion Grp., LLC v. Plaquemines Par. Gov't, 2025-0356 (La. App. 4 Cir. 1/7/26), 430 So. 3d 1175, writ denied, 2026-00217 (La. 5/12/26), 430 So. 3d 1090.

‍

The Louisiana Supreme Court recently ruled a plaintiff’s bad faith insurance claim was prescribed where the policy at issue required actions to be brought within two years after the date of loss.

In Phyllis Wilson v. Louisiana Citizens Property Insurance Corporation, the plaintiff asserted a bad faith claim against an insurer. The applicable policy of insurance provided “[n]o action can be brought unless the policy provisions have been complied with and the action is started within two years after the date of loss.” The plaintiff alleged that the insurer failed to timely tender payments for losses that occurred on August 27, 2020 and October 20, 2020. However, the plaintiff did not file her suit unit January 9, 2023.

Prior to the Wilson decision, courts frequently relied on the Louisiana Supreme Court’s decision in Smith v. Citadel Ins. Co., which held that actions against insurers under Louisiana’s bad faith statutes are subject to a ten-year prescriptive period. In Smith, the Supreme Court addressed the issue of whether a bad faith action against an insurer was a delictual or tort action subject to a one-year prescriptive period, or a contractual action, which is subject to a ten-year prescriptive period under Louisiana law. The Smith court concluded that the duty of good faith owed by the insurer to the insured “emanates from the contract between the parties” such that the “insured’s cause of action is personal and subject to a ten-year prescriptive period.”

In Wilson, the Louisiana Supreme Court examined whether Smith required the Court to uphold a ten-year prescriptive period for bad faith actions even though the insurance policy at issue prohibited actions brought more than two years after the date of loss. The Wilson court ultimately concluded that an action against an insurer brought more than two years after the date of loss is prescribed where the applicable insurance policy set a term of two years for filing a claim against the insurer.

To reach this conclusion, the Wilson court cited Taranto v. Louisiana citizens Prop. Ins. Corp., which held “in the absence a statutory prohibition, a clause in an insurance policy fixing a reasonable time to institute suit is valid.” The Wilson court then turned to the applicable statute and noted that La. R.S. 22:868(B) “expressly provides that no policy ‘shall contain any condition, stipulation, or agreement limiting right of action against the insurer to a period of less than twenty-four months next after the inception of the loss when the claim is a first-party claim…’” The Wilson court noted the two-year limitation in the applicable policy was consistent with La. R.S. 22:868(B).

The court’s ruling supports the argument that policy provisions requiring actions to be filed within two years of the date of loss are enforceable. However, the Court did not disturb its holding in Smith, noting the Smith case was factually distinguishable because it did not involve a policy that contained a contractual limitation on the insured’s institution of suits.

References:

Phyllis Wilson v. Louisiana Citizens Property Insurance Corporation, No. 2023-CC-01320 (La. 1/10/2024) (per curiam), 2024 WL 108714.

Smith v. Citadel Ins. Co., 2019-00052 (La. 10/22/19), 285 So.3d 1062.

Taranto v. Louisiana citizens Prop. Ins. Corp., 2010-0105 (La. 3/15/11), 62 So.3d 721, 728.

In Rowland v. BASF, 20- 278 (La. App. 1 Cir. 3/29/21), 2021 WL 1170326, the Louisiana First Circuit Court of Appeal ruled that a claim for death benefits filed by a widow whose husband died from an occupational disease was not prescribed, even though her deceased husband’s claim for workers’ compensation benefits would have been time-barred.

The claimant’s husband was exposed to asbestos from 1969 to 1989 while working for BASF. He was diagnosed with occupationally-related asbestos in 2001 and passed away on July 27, 2018. A claim for Workers’ compensation death benefits against BASF was filed on December 26, 2018.

BASF filed an “Exception of Prescription &/or Motion for Summary Judgment” and argued the widow’s claim was derivative of her husband’s cause of action. BASF contended that, because the employee’s claim would have been prescribed, her claim for death benefits also prescribed. In response, the claimant argued suit was timely because it was filed within one year of the employee’s death as required by La. R.S. 23:1031.1(F). The Worker’s compensation trial judge granted the exception of prescription.

The First Circuit reversed, accepting the claimant’s argument that the claim was timely because it was filed within one year of death. The court rejected BASF’s argument that the death benefit claim could be pursued only if the deceased husband had filed a Worker’s comp claim prior to his death.

In support of dismissal, BASF also cited La. R.S. 23:1231(A), which provides there is no right of action to pursue death benefits if the claim is not filed within two years of the employee’s last treatment. However, the Rowland court did not address this issue because BASF had not filed an Exception of No Right of Action and did not factually establish when the deceased employee last received treatment for asbestos. Moving forward, the viability of the claim will depend upon whether her husband died within two years of the last treatment related to the occupational disease.