When No Higher Court Remains

The Supreme Court ruling in Couvillion Group, LLC v. Plaquemines Parish Government, 2020 -00074 (La. 4/27/20) is a reminder that an indemnity claim must be sufficiently related to the principal demand and that contract indemnity provisions are to be strictly construed.

In Couvillion, the general contractor sued the owner of a public works port project for contract delay damages resulting from a cease work order issued to allow redesign of a fuel tank platform. When the contractor submitted its delay claim, the owner requested that its project engineer review it and make recommendations. The engineer recommended payment of a little over $1 million dollars. When the owner refused to pay, the contractor sued. In response, the owner filed a third-party demand against the engineer alleging that its recommendation was erroneous and excessive and that, if it was bound by the engineer’s recommendation, then the engineer must indemnify the owner.

On behalf of the engineer, Keogh Cox attorneys argued that the engineer should not be required to reimburse the owner for any delay costs and asked for dismissal through an exception of no cause of action. Code of Procedure Article 1111 provides that a defendant in a principal action may bring in any person who may be liable to him for all or part of the principal demand. Here, that was not the situation. The engineer was not liable to the owner for any part of the contractor’s delay claim because the engineer did not cause the delay. The delay damages were incurred before the engineer made a recommendation for payment. The events giving rise to the two claims were separate and distinct: the main demand arose from the project delay and the third- party demand arose from the engineer’s recommendation of the claim amount. The Court commented that the principal claim against the owner for delay damages was too attenuated from the owner’s claim against the engineer, thus the third-party demand was improper.

The owner also relied on the indemnity provision in the engineer’s contract that required the engineer to indemnify the owner against any and all claims for personal injury or “damages to property” that may arise from its services. The Court held that the plain meaning of the term did not include the economic-only losses related to the subject delay claim. The Court further reasoned that indemnity agreements are to be strictly construed, rejecting the owner’s broader interpretation.

Keogh Cox attorneys Andrew Blanchfield, Chris Jones, and Chelsea Payne successfully defeated class certification in an action students brought to recover a partial refund of tuition and fees they claim they were owed after in-person classes were converted to remote learning because of the COVID-19 global pandemic. See Miazza v. Board of Supervisors of Louisiana State University and Agricultural and Mechanical College.

In 2021, plaintiffs Taylor Gunter and Michael Miazza filed a lawsuit seeking a partial refund of the tuition they paid to LSU for Spring 2020 classes. They alleged that they were entitled to a partial refund of tuition and certain fees because in-person classes were cancelled in the wake of the COVID-19 pandemic. In lieu of in-person classes, remote learning went into effect after spring break, from March 30, 2020 through the end of the spring semester.

In addition to their own claims for partial refunds, the plaintiffs tried to bring the case as a class action and moved to certify a class defined as: “All students who, as of March 13, 2020, were enrolled at Louisiana State University's main campus in Baton Rouge who paid Tuition and/or Fees for the Spring 2020 semester, or on whose behalf such payment was made.”

After the completion of discovery for class certification, and after the dismissal of Plaintiff Michael Miazza’s claim, Plaintiff Taylor Gunter filed a Motion for Class Certification. After hearing, the Trial Court certified the class as alleged, finding all the requirements for class certification set forth in La. C.C.P. art. 591 were satisfied. LSU appealed the decision to the First Circuit Court of Appeals.

The First Circuit reversed the Trial Court’s judgment and found the Plaintiff failed to satisfy all of the requirements for class certification. After conducting a rigorous analysis of the class certification requirements, the Court concluded that “a multitude of individualized inquiries and proof make up the liability and damages issues essential to the putative plaintiffs’ implied contract claims.” The Court identified some of these “individualized inquiries” as follows:

• which representations in each school’s or college’s catalogs, bulletins, and website materials did the putative plaintiff rely upon in developing his or her expectation and what particular facilities and on-campus opportunities did a putative plaintiff expect to utilize;

• whether the putative plaintiff has historically utilized on-campus facilities and opportunities; which facilities and/or on-campus opportunities, if any, were necessary for a particular school's or college's course completion;

• whether a putative plaintiff was satisfied with the online instruction, course credits received, and grading options provided; and

• whether a putative plaintiff actually suffered any financial loss, mindful of each student’s particular situation.

Ultimately, the Court concluded that the record lacked sufficient evidence to support findings of offers and acceptances, where were necessary (1) to establish meetings of the mind and (2) conclude each putative plaintiff and LSU consented to an implied contract. Any determination of liability for an implied contract also is dependent upon proof of facts individual to each putative class member. Therefore, the class would degenerate into a series of individual trials.

The First Circuit concluded that certification of the case as a class action was an abuse of discretion. It reversed the Trial Court’s judgment and decertified the matter. Plaintiff filed a Writ Application with the Louisiana Supreme Court. On January 14, 2025, the Louisiana Supreme Court denied Plaintiff’s Writ Application, finally resolving the class certification issue. As a result, Plaintiff cannot pursue class certification, but rather may only pursue her own individual claim.

References:

Miazza v. Board of Supervisors of Louisiana State University and Agricultural and Mechanical College, 2023-1194 (La. App. 1 Cir. 8/9/24), 394 So.3d 874, writ denied, 2025 WL 87255 (La. 1/14/25).

The United States District Court for the Eastern District of Louisiana grants defendant, Circle K's, Motion to Dismiss concluding that plaintiff has no right to claim loss of opportunity to win the Louisiana Lottery Powerball jackpot, $103,100,000.00, because of an expired ticket issued in error.

This matter arose from plaintiff's purchase of two sets of Powerball tickets on or about January 19, 2012. The drawing that was the subject of the purchase was to be held on January 21, 2012 with a jackpot of $103,100,000.00. Sometime after the drawing date, plaintiff discovered the purchased tickets were printed on January 18, 2012 and worthless for the January 21, 2012 drawing. Plaintiff filed suit seeking damages in the amount of the Powerball jackpot.

After removal to Federal Court, on behalf of Circle K, Keogh Cox moved to dismiss the suit by claiming that Louisiana law affords no relief to plaintiff for the alleged claims. Specifically, Louisiana law explicitly precludes any relief to the plaintiff.

Keogh Cox cited La. R.S. 47:9009 which states "that there shall be no liability on the part of and no cause of action shall arise against the corporation, its governing board, staff, agents, vendors, or employees, arising out of or in connection with the issuance, failure to issue, or delivery of a lottery ticket."

Moreover, Keogh Cox asserted that the Louisiana Statute precludes payment of prize money on the basis of lottery tickets produced or issued in error. The United States District Court found merit in these assertions after extensive briefing and arguments by Keogh Cox attorneys, John P. Wolff, III, Nancy B. Gilbert, Richard W. Wolff and Mark Assad.

The United States District Court found that Circle K was statutorily exempt from the suit and, under the directives of the lottery itself, it is the sole responsibility of plaintiff to verify the accuracy of the game play. Plaintiff failed to do so and, as such, was barred from suit.